Terms & Conditions

1. Introduction

Welcome to OMIKON Construction Limited. By accessing or using our website, services, or contacting us, you agree to comply with and be bound by these Terms and Conditions.
If you do not agree with any part of these terms, please do not use our website or services.

2. Company Information

OMIKON Construction Limited
43 Carnarvon Road, Stratford, London, United Kingdom
Postcode: E15 4JW
Email: Enquiry@omikon.co.uk
Phone: +44 7404 954453

3. Services

OMIKON Construction Limited provides construction, renovation, project management, and related services. All project timelines, budgets, and deliverables are agreed upon through written contracts or quotations before work commences.

4. Quotations & Payments

All quotations provided are valid for a limited period, as stated on the quotation document.
Payments must be made as per the agreed schedule. Delayed payments may result in project delays or additional charges.

5. Project Timelines

While we strive to meet agreed completion dates, unforeseen factors such as weather conditions, material availability, or external approvals may cause reasonable delays. OMIKON Construction Limited is not liable for delays outside our control.

6. Client Responsibilities

Clients must provide site access, necessary permissions, and accurate project information. Any changes or additions to the agreed scope of work may result in revised costs or timelines.

7. Liability

OMIKON Construction Limited shall not be liable for any indirect, incidental, or consequential damages arising out of the use or inability to use our services. Our total liability shall not exceed the total contract value of the specific project.

8. Intellectual Property

All website content, designs, text, and images are the property of OMIKON Construction Limited and may not be reproduced without written consent.

9. Governing Law

The laws of England and Wales govern these Terms & Conditions. Any disputes shall be subject to the exclusive jurisdiction of the courts of London, United Kingdom.

10. Contact

For any queries regarding these Terms, don't hesitate to get in touch with us at:
📧 Enquiry@omikon.co.uk | 📞 +44 7404 954453